Last updated: 29/03/2025
Welcome to Msigns. These Terms and Conditions govern your access to and use of our website, services, and products. By engaging our services or accessing our website, you agree to comply with and be bound by the following Terms and Conditions, which, together with our Privacy Policy and any signed proposals or contracts, constitute a legally binding agreement between you and Msigns.
Msigns is a UK-based signage company specialising in exterior signage solutions, including bespoke 3D lettering, signage design, manufacture, installation, and maintenance. With over 7 years of experience, we serve businesses throughout the UK, including high-profile clients such as Screwfix and Subway.
Quotations are provided free of charge and are valid for 15 days from the date of issue unless otherwise stated.
An order is only deemed accepted when the Client has confirmed acceptance of the quotation in writing (email is sufficient), and the agreed deposit or upfront payment has been received in cleared funds.
Work will commence only after written acceptance of the quote, receipt of required deposit, and confirmation of all design proofs and site conditions, where applicable.
If the Client cancels an order after project commencement, they will be liable for the cost of all materials ordered or work undertaken up to the cancellation date, any restocking or reprint charges, and a cancellation fee of up to 30% of the total quote for lost time and scheduling disruption.
Prices quoted are exclusive of VAT unless otherwise stated. Prices may vary depending on the final specifications, materials, size, installation complexity, or time constraints.
Unless agreed otherwise in writing, a 50% non-refundable deposit is required before production begins. The remaining 50% is payable upon completion and prior to delivery or installation.
We accept payment via BACS, bank transfer, or approved business cheques. Payment details will be provided on invoices.
Failure to make payment by the agreed due date will result in interest being charged at 8% per annum above the Bank of England base rate, in line with the Late Payment of Commercial Debts (Interest) Act 1998, possible withholding of deliverables, and legal action or debt recovery procedures.
All design concepts remain the property of Msigns unless otherwise agreed in writing. We retain copyright on all original artwork and concepts.
Clients are responsible for carefully reviewing and approving all proofs before production. Once a proof is signed off, Msigns is not liable for any errors, omissions, or misunderstandings, and any corrections or modifications may incur additional charges.
Digital visuals are representations and may vary slightly in scale or colour when produced, especially due to lighting conditions, printing processes, or materials used.
Estimated production and delivery/installation timelines will be communicated at project commencement. Delays may arise due to material supply issues, adverse weather conditions, site access constraints, or client-induced delays such as delayed approvals.
Clients must ensure safe and unrestricted access to the site for installation. Delays or rescheduling caused by access issues may incur additional costs.
Clients must inform Msigns of any known hazards on-site. Msigns reserves the right to pause or reschedule installations that pose safety concerns.
It is the Client's responsibility to obtain any required local authority permits or landlord permissions unless Msigns has explicitly agreed to do so in writing.
We offer a 12-month warranty on all signage installations against manufacturing defects under normal use.
The warranty does not cover accidental damage, vandalism, wear and tear due to adverse environmental conditions, or improper installation by third parties.
To the fullest extent permitted by law, Msigns shall not be liable for indirect, incidental, or consequential loss, and our liability shall not exceed the total fees paid by the Client for the specific project.
All intellectual property developed by Msigns remains our property unless agreed otherwise in a separate contract. Clients may not reproduce, resell, modify, or distribute any of our work without prior written permission.
Where Clients supply logos, branding elements, or content, the Client warrants that they have legal rights to use such materials. Msigns accepts no liability for infringement of third-party rights based on client-supplied content.
Msigns shall not be liable for delays, failures, or damages caused by events beyond our reasonable control, including natural disasters, strikes or industrial disputes, acts of terrorism, power outages, or supplier failures.
You may browse our website and access publicly available content for personal or business use, subject to the following restrictions:
We reserve the right to suspend or block access to our website for any user violating these terms.
We are fully compliant with the UK General Data Protection Regulation (UK GDPR) and Data Protection Act 2018. By engaging with us, you agree to our Privacy Policy, which outlines what data we collect, how it is used, and your rights.
We do not sell or share client data with third parties for marketing purposes.
We reserve the right to suspend or terminate a project or agreement in the event of non-payment, repeated communication breakdowns, abuse or threatening behaviour, or breach of these Terms. Any unpaid fees or costs incurred up to the point of termination remain due.
We aim to resolve disputes amicably and professionally. Clients are encouraged to contact us promptly if dissatisfied with any aspect of our service. If a dispute cannot be resolved directly, either party may seek recourse through mediation or the courts.
These Terms shall be governed by and construed in accordance with the laws of England and Wales. All disputes shall be subject to the exclusive jurisdiction of the courts of England.
We may amend these Terms from time to time without prior notice. The most recent version will always be posted on our website. Continued use of our services after such changes constitutes acceptance.
Using our website and services, you acknowledge that you have read and understood this Terms & Conditions. Thank you for trusting Manchester Signs Centre. See also our Privacy Policy and Terms & Conditions.
Join 100s of Manchester businesses who trust Manchester Signs Centre. Free design, fast turnaround, professional installation.